Building Contract Template UK

The Building Contract Template UK is offered in multiple formats, including PDF, Word, and Google Docs, featuring both editable and printable versions for your convenience.

Open – Template

Online – Template

Sample

Building Contract Template UK

Editable – Printable

PDF – 1 PDF – 2

Building Contract Template UK

1. Client Information


2. Contractor Information


3. Project Details


4. Scope of Work

5. Client Responsibilities

6. Contractor Responsibilities

7. Payment Terms

8. Homeowner’s Insurance

9. Change Orders

10. Dispute Resolution

11. Termination Clauses

12. Declaration and Signatures



PDF

WORD

Examples

Building Contract Template UK (1)
Between:
[Name of the Client]
[Client’s ID]
[Client’s Address]
[Client’s Phone]
[Client’s Email]
And:
[Name of the Contractor]
[Contractor’s ID]
[Contractor’s Address]
[Contractor’s Phone]
[Contractor’s Email]
Introduction:
This agreement outlines the terms and conditions under which [Name of the Contractor] will carry out building works for [Name of the Client], commencing on [Start Date].
Clause 1: Scope of Work
The Contractor agrees to execute the following works: [Detailed description of works to be completed, e.g., construction of residential house, renovations, extensions].
Clause 2: Contract Sum
The total cost for the works shall be [Amount], to be paid according to the following schedule: [Payment Schedule, e.g., deposit, progress payments, final payment].
Clause 3: Duration of Works
The estimated duration for completion of the works is [Duration, e.g., 6 months], starting from the date of commencement.
Clause 4: Change Orders
Any changes to the scope of work must be documented and approved through a written change order, which may alter the contract sum and/or duration.
Clause 5: Health and Safety
The Contractor shall comply with all relevant health and safety regulations and ensure the site is safe for workers and visitors at all times.
Clause 6: Liens and Encumbrances
The Contractor warrants that all materials and works shall be free of liens and other encumbrances at the time of completion.
Signed in [City], [Date].
Sincerely,
[Signature of the Client]
[Name of the Client]
[Signature of the Contractor]
[Name of the Contractor]
Building Contract Template UK (2)
Between:
[Name of the Client]
[Client’s ID]
[Client’s Address]
[Client’s Phone]
[Client’s Email]
And:
[Name of the Contractor]
[Contractor’s ID]
[Contractor’s Address]
[Contractor’s Phone]
[Contractor’s Email]
Introduction:
This contract formalizes the agreement for construction services provided by [Name of the Contractor] to [Name of the Client] starting on [Start Date].
Clause 1: Detailed Description of Services
The Contractor shall perform the following services: [List specific services, e.g., foundation work, roofing, electrical installations, and plumbing].
Clause 2: Payment Terms
The Client agrees to pay the Contractor according to a schedule: [Specify amounts and timing for each payment, including any deposit required].
Clause 3: Completion Date
The estimated completion date for the project is [Completion Date], subject to adjustments as per circumstances outlined in this contract.
Clause 4: Warranties and Guarantees
The Contractor shall provide warranties for the workmanship and materials for a period of [Warranty Duration, e.g., 1 year] after project completion.
Clause 5: Dispute Resolution
In the event of any dispute under this agreement, the parties agree to resolve the matter through arbitration before pursuing litigation.
Clause 6: Governing Law
This contract shall be governed by the laws of [Jurisdiction, e.g., England and Wales], without regard to its conflict of laws provisions.
Signed in [City], [Date].
Sincerely,
[Signature of the Client]
[Name of the Client]
[Signature of the Contractor]
[Name of the Contractor]

Printable

PDF – 1 PDF – 2

Building Contract Template UK